SAICE

JBCC Direct Contractor’s Contract

R710,00 Incl. VAT

Product Code: TD/JBC/CDCCC
This JBCC Direct Contractor’s Contract is intended for use where an employer elects to appoint, prior to practical completion, a contractor directly to perform work where a main contractor has been appointed under the JBCC Principal Building Agreement, Minor Works Agreement or Small and Simple Works Contract.

Additional information

Weight 500 g
Author

–
Publisher

Joint Building Contracts Committee
Edition

Edition 1.0
Year

May 2020

TABLE OF CONTENTS

1.0 DEFINITIONS AND INTERPRETATION

Definitions

Interpretation

Offer and acceptance

Document

Assignment

2.0 INSURANCES

3.0 EXECUTION, SETTING OUT AND PROGRAMME

Execution

Setting out

Programme

4.0 PAYMENT

5.0 ADJUSTMENT OF THE QUOTATION AMOUNT

6.0 CONTRACT INSTRUCTION

7.0 COMPLETION

8.0 REVISION OF THE DATE FOR COMPLETION

9.0 TERMINATION

Termination

Termination procedure

10.0 DISPUTES

Settlement by the parties

Mediation

Adjudication

Arbitration

General

11.0 CONTRACT DATA

11.1 INFORMATION BY THE EMPLOYER

Project information

Changes made to the JBCC documentation

Tender closing

11.2 INFORMATION BY THE DIRECT CONTRACTOR

Direct contractor information

Tender conditions, amount compilation and qualifications